Closed ATM View - DNP-PAI-2122-703-BNP
Civil Engineering Services at Booderee National Park
The Customer is seeking the services of a suitably qualified and experienced engineering firm to provide engineering design and specification, stakeholder consultation, construction supervision and certification for the Works.
The Works will require the Supplier to develop a strong, trusted and consultative relationship with BNP staff, DITRDC staff, WBACC Council staff, and the construction contractor.
The successful tenderer will work with the nominated Customer’s representative to deliver the services and will work with the civil contractor engaged by the Customer. It is intended that one civil contractor will be engaged to complete all the construction works, so Tender Stage Services for the two packages of work will be combined.
The Customer will exclude from consideration any Response that does not meet the following Mandatory Conditions for Participation:
1. The respondent must exist as a legal entity. The respondents answer must be a Yes or No.
2. Site Inspection - Potential Suppliers who do not attend the site inspection, detailed at A.A.1, will be excluded from consideration.
Due Date |
Milestone Description |
17 March 2022 |
Completion of User Requirements Brief for Depot carpark |
19 May 2022 |
Cable location, survey and geotechnical investigations for Depot carpark |
19 May 2022 |
Cable location, survey and geotechnical investigations for Visitor Centre carpark and entrance |
19 May 2022 |
Completion of Design stage services for Depot carpark |
19 May 2022 |
Completion of Design stage services for Visitor Centre carpark and entrance |
30 July 2022 |
Completion of Tender stage services for Depot carpark, Visitor Centre carpark and entrance (including Ellmoos Rd ‘braking zone’) |
30 September 2022 |
Completion of Construction stage services (Practical completion) for Depot carpark |
30 September 2022 |
Completion of Construction stage services (Practical completion) for Visitor Centre carpark and entrance (including Ellmoos Rd ‘braking zone’) |